JUSTICE V.K.JAIN, PRESIDING MEMBER (ORAL)

CONSUMER COMPLAINT NO. 471 OF 2017   

      The complainants namely Rohit Chopra and Mrs. Vijay Lakshmi Chopra booked a residential villa with the OP in a project namely ‘Espace Premiere’, which the OP is developing in Nirvana Country-2, Sector-71 & 72 of Gurgaon.  Vide allotment letter dated 09.03.2011, house no. 0132 in Block-B in the aforesaid project was allotted to the complainants for a consideration of Rs.2,35,30,104/-.  The parties then executed an agreement dated 22.03.2011 incorporating their respective obligations in respect of the said transaction.  In terms of clause 4.a(i) of the said agreement, the possession was to be delivered within 24 months of the execution of the agreement.  The possession therefore, ought to have been delivered by 22.03.2013.  The grievance of the complainants is that the possession has not been delivered to them despite they having already paid Rs.1,60,02,015/- to the OP.  The complainants are therefore, before this Commission seeking possession of the aforesaid villa/house alongwith compensation.

CONSUMER COMPLAINT NO. 564 OF 2017

       The complainants namely Om Prakash Chopra and Mrs. Sunita Chopra booked a residential villa with the OP in a project namely ‘Espace Premiere’, which the OP is developing in Nirvana Country-2, Sector-71 & 72 of Gurgaon.  Vide allotment letter dated 02.02.2012, house no. 0092 in Block-B in the aforesaid project was allotted to the complainants for a consideration of Rs.2,31,70,104/-.  The parties then executed an agreement dated 10.02.2012 incorporating their respective obligations in respect of the said transaction.  In terms of clause 4.a(i) of the said agreement, the possession was to be delivered within 24 months of the execution of the agreement.  The possession therefore, ought to have been delivered by 10.02.2014.  The grievance of the complainants is that the possession has not been delivered to them despite they having already paid Rs.1,47,53,915/- to the OP.  The complainants are therefore, before this Commission seeking possession of the aforesaid villa/house alongwith compensation.

CONSUMER COMPLAINT NO. 807 OF 2017                 

         One Dr. Harish Kumar Sidhwa and Dr. Rajni Sidhwa booked a residential villa with the OP in a project namely ‘Espace Premiere’, which the OP is developing in Nirvana Country-2, Sector-71 & 72 of Gurgaon and house no. 0098 in Block-B in the aforesaid project was allotted to them for a consideration of Rs.1,83,38,104/-.  The parties then executed a Buyers Agreement with the OP dated 22.12.2011 and in their case also, the possession was to be delivered within 24 months of the execution of the Buyers Agreement.  The possession therefore, ought to have been delivered by 22.12.2013.  The aforesaid villa/house was purchased by the complainant namely Rajnish Kehair from Dr. Harish Kumar Sidhwa and Dr. Rajni Sidhwa on 10.05.2013.  The allotment was thereafter, transferred by the OP in favour of the complainant vide its letter dated 10.05.2013.  The grievance of the complainant is that the possession of the villa/house has not been offered to him despite he and his predecessors having paid Rs.98,75,189/- to the OP.  He is therefore, before this Commission, seeking possession of the aforesaid villa/house alongwith compensation. 

2.      The OP did not file its written version despite service and its right to file the said written version was closed vide order dated 25.01.2018. 

3.     I have heard the learned counsel or the parties and have considered the affidavits by way of evidence filed by the complainants.

4.       The learned counsel for the complainants submits that though no written version contesting the complaints has been filed, several other consumer complaints pertaining to allotment of houses/villas in this very project have already been allowed by this Commission in CC No. 368 of 2015 Sudhanshu Pokhriyal Vs. Unitech Ltd., decided on 03.05.2017 and CC No. 603 of 2014 Capt. Gurtaj Singh Sahni & Anr. Vs. Unitech Limited & Anr. and connected matters, decided on 02.05.2016.

5.       The decision of this Commission in Sudhanshu Pokhriyal (supra) to the extent it is relevant, reads as under:

2.       The complaint has been resisted by the OP on the grounds which this Commission has already rejected in several consumer complaints.  It is inter-alia stated in the reply filed by the opposite party that the construction of the project was affected due to shortage of water since the Hon’ble Punjab & Haryana High Court, vide order dated 16.07.2012, stopped the usage of underground water and directed use only of the treated water from the available Sewerage Treatment Plants. Since the availability of the sewerage treatment plants and water from such plants is very limited as compared to the requirement, it became difficult to maintain the timely schedule of construction. Relying upon clause 4(a) of the Buyers Agreement, it is claimed that the completion of the construction has been delayed on account of circumstances beyond the control of the opposite party. Relying upon clause 4(e), it is stated that in case the developer is unable to offer possession, it is liable either to offer an alternative property or to refund the amount received from the buyer alongwith interest @ 10% per annum. It is also claimed that as per clause 4(c)(iii) of the Buyers Agreement, in case of delay in delivering possession, the buyer is entitled to compensation @ Rs. 50/- per sq. yd. per month for the period the possession is delayed.

3.       In Captain Gurtaj Singh Sahni & Anr. Vs. Manager, Unitech Limited & Anr. and connected cases,  this Commission while allowing the complaints filed by the buyers of residential villa in the above referred project namely ‘Espace Premiere’, Nirvana Country-2, Sector-71 & 72, Gurgaon inter-alia held as under:

“3.      It would thus be seen that admittedly, the opposite party had entered into Buyers Agreement with the complainants and promised to offer possession within two years from the date on which the said Buyers Agreements were executed. It is also not in dispute that the opposite party has not been able to complete the construction of the villa though more than 1½ years have already expired from the date by which the last villa was to be handed over and more than three years have expired from the date by which the first villa was to be offered. Thus, the opposite party is at least 1½ years behind schedule in each case and it is not known when it would be able to complete the construction.

4.      During the course of hearing, I asked the representative of the opposite party to inform as to when it will be able to complete the construction of the villas and offer possession to the complainants. She states on instructions that the construction was likely to be completed within one year from the date on which it resumes but the opposite party cannot commit any particular date for resuming the construction of the villas.

5.      Since it is an admitted position that the opposite party had entered into Buyers Agreements with the complainants and deliver possession to them within 24 months of the said agreements, the direction sought by those complainants for completing the construction of the villas in a time bound manner is eminently justified in the facts and circumstances of the case. Taking into consideration all the facts and circumstances of the case, the opposite party, in my opinion, should resume the construction within three months from today, complete the same in all respects within one year thereafter and offer possession after obtaining the requisite completion certificate, within three months thereafter. Thus, the villas after completion of construction and obtaining the requisite completion certificate should be offered to the complainants on or before 18 months from the date of this order.

6.      The next question which arises for consideration is the quantum of compensation which should be paid to the complainants for the delay in completion of the villas. As far as the prohibition on use of underground water in construction is concerned, the learned counsel for the complainant has drawn my attention to the order dated 21.08.2012 passed by a Divisional Bench of Punjab & Haryana High Court in Civil Writ Petition No. 20032 of 2008 wherein the High Court noted that the public notice issued under Section 5(3) of the Environment Protection Act, 1986 was published in the newspaper on 26.12.2000. It further shows that the said notice had imposed a complete ban upon the use of underground water in the construction without prior approval of the competent authority. It was noted by the High Court that despite publication of the aforesaid notice, the builders continued to use underground water for construction purposes. If there was a complete ban on use of underground water for construction and the said prohibition was notified on 26.12.2000, the opposite party must have taken into account, the impact of the said prohibition while entering into Buyers Agreements with the complainants. Therefore, it is not open to the opposite party to rely upon the said prohibition in order to justify the delay in construction of the villas sold to the complainants. The opposite party knew at the time of entering into agreements with the complainants that it will not be able to use underground water for construction of the villas and therefore, will have to make alternative arrangements from authorized sources for making the water available for the said construction. Therefore, the aforesaid prohibition on use of the underground water for construction purpose does not justify the delay in completion of the construction. In any case, no material has been placed by the opposite party on record to show that efforts were made by it during the relevant period to procure water from alternative sources but it was unable to obtain the water from the said sources. More importantly, in the Buyers Agreement executed between the parties, it was not disclosed to the buyers that since no underground water can be used for construction purpose, the developer will have to arrange water from alternative sources and in case it is not able to arrange water, the construction would be delayed and in that case, it will not be held responsible for the delay in completion of the construction.”

4.       The learned counsel for the OP states on instructions that the construction of the villa has started in December 2016, though she admits that the possession of construction is very slow.  She is not in a position to commit any particular time period for completion of construction and delivery of possession of the villa to the complainant. 

6.        For the reasons stated hereinabove, the complaints are disposed of with the following directions:

1. In each complaint, the OP shall complete the construction of the villas/houses allotted to the complainants in all respects, obtain the requisite occupancy certificates and offer their possession to all the three complainants, on or before 31.12.2019.

2. In CC No.471 of 2017 and CC No. 564 of 2017, the OP shall pay compensation to the complainants in the form of simple interest @ 8% per annum from the committed date of possession, till the date on which the possession in terms of this order is actually offered.

3. In CC No. 807 of 2017, the OP shall pay compensation in the form of simple interest @ 8% per annum, with effect from 10.05.2015 till the date on which the possession is actually offered in terms of this order.The aforesaid complainant will also be entitled to contractual compensation for the period from 22.12.2013 till 09.05.2015.

4. The additional amount if any, payable by the complainants to the OP, shall be adjusted out of the compensation payable to the complainants in terms of this order and balance amount if any, shall be paid to them on or before the date on which the possession in terms of this order is actually suffered.

5. The OP shall also pay a sum of Rs.25,000/- as the cost of litigation to the complainants in each complaint.

6. The OP shall not create any third party interest in the villas/houses allotted to the complainants till possession in terms of this order is actually delivered to them.