ORDER (ORAL)

JUSTICE V.K.JAIN, PRESIDING MEMBER (ORAL)

The complainant has booked a residential flat with the opposite party in a project namely East Space Premie, Nirwana Country II, which the opposite party Unitech Ltd. was to develop in Gurgaon.  Vide allotment letter dated 28.01.2012, house no. BH-0045, in the aforesaid project was allotted to the complainant for a consideration of Rs.2,66,15,342/-.  The parties then executed buyers’ agreement dated 13.02.2012, recording their respective obligation in respect of the aforesaid allotment.  In terms of clause 4(a)(1i) of the agreement the possession of the house was to be delivered within 24 months of its execution.  The possession therefore ought to have been delivered by 13.12.2014.  The grievance of the complainant is that the possession of the house has not been delivered to her despite she having already paid 1,42,55,764/- to the opposite party.  The complainant is therefore, before this Commission seeking possession of the aforesaid house alongwith compensation etc.

2. The opposite has filed written version contesting the complaint. But the learned counsel for the complainant submits that the complaint has been resisted on the ground which this Commission has already rejected in several decisions and therefore, those grounds need not be considered again.

3.      I have heard the learned counsel for the complainant and have considered the affidavits filed by the parties by way of evidence.

4.      The opposite party has not disputed the allotment made to the nor it has disputed execution of the buyers’ agreement with her.  The payment made by the complainant has also not been disputed.  It is also not in dispute that the possession of the house has not been delivered to the complainant.

5.      In Sudhanshu Pokhriyal vs. Unitech Ltd., in C.C. No. 368/2014 decided on 03.05.2017, this Commission inter-alia held as under:-

2.       The complaint has been resisted by the OP on the grounds which this Commission has already rejected in several consumer complaints.  It is inter-alia stated in the reply filed by the opposite party that the construction of the project was affected due to shortage of water since the Hon’ble Punjab & Haryana High Court, vide order dated 16.07.2012, stopped the usage of underground water and directed use only of the treated water from the available Sewerage Treatment Plants. Since the availability of the sewerage treatment plants and water from such plants is very limited as compared to the requirement, it became difficult to maintain the timely schedule of construction. Relying upon clause 4(a) of the Buyers Agreement, it is claimed that the completion of the construction has been delayed on account of circumstances beyond the control of the opposite party. Relying upon clause 4(e), it is stated that in case the developer is unable to offer possession, it is liable either to offer an alternative property or to refund the amount received from the buyer alongwith interest @ 10% per annum. It is also claimed that as per clause 4(c)(iii) of the Buyers Agreement, in case of delay in delivering possession, the buyer is entitled to compensation @ Rs. 50/- per sq. yd. per month for the period the possession is delayed.

3.       In Captain Gurtaj Singh Sahni & Anr. Vs. Manager, Unitech Limited & Anr. and connected cases,  this Commission while allowing the complaints filed by the buyers of residential villa in the above referred project namely ‘Espace Premiere’, Nirvana Country-2, Sector-71 & 72, Gurgaon inter-alia held as under:

“3.      It would thus be seen that admittedly, the opposite party had entered into Buyers Agreement with the complainants and promised to offer possession within two years from the date on which the said Buyers Agreements were executed. It is also not in dispute that the opposite party has not been able to complete the construction of the villa though more than 1½ years have already expired from the date by which the last villa was to be handed over and more than three years have expired from the date by which the first villa was to be offered. Thus, the opposite party is at least 1½ years behind schedule in each case and it is not known when it would be able to complete the construction.

4.      During the course of hearing, I asked the representative of the opposite party to inform as to when it will be able to complete the construction of the villas and offer possession to the complainants. She states on instructions that the construction was likely to be completed within one year from the date on which it resumes but the opposite party cannot commit any particular date for resuming the construction of the villas.

5.      Since it is an admitted position that the opposite party had entered into Buyers Agreements with the complainants and deliver possession to them within 24 months of the said agreements, the direction sought by those complainants for completing the construction of the villas in a time bound manner is eminently justified in the facts and circumstances of the case. Taking into consideration all the facts and circumstances of the case, the opposite party, in my opinion, should resume the construction within three months from today, complete the same in all respects within one year thereafter and offer possession after obtaining the requisite completion certificate, within three months thereafter. Thus, the villas after completion of construction and obtaining the requisite completion certificate should be offered to the complainants on or before 18 months from the date of this order.

6.      The next question which arises for consideration is the quantum of compensation which should be paid to the complainants for the delay in completion of the villas. As far as the prohibition on use of underground water in construction is concerned, the learned counsel for the complainant has drawn my attention to the order dated 21.08.2012 passed by a Divisional Bench of Punjab & Haryana High Court in Civil Writ Petition No. 20032 of 2008 wherein the High Court noted that the public notice issued under Section 5(3) of the Environment Protection Act, 1986 was published in the newspaper on 26.12.2000. It further shows that the said notice had imposed a complete ban upon the use of underground water in the construction without prior approval of the competent authority. It was noted by the High Court that despite publication of the aforesaid notice, the builders continued to use underground water for construction purposes. If there was a complete ban on use of underground water for construction and the said prohibition was notified on 26.12.2000, the opposite party must have taken into account, the impact of the said prohibition while entering into Buyers Agreements with the complainants. Therefore, it is not open to the opposite party to rely upon the said prohibition in order to justify the delay in construction of the villas sold to the complainants. The opposite party knew at the time of entering into agreements with the complainants that it will not be able to use underground water for construction of the villas and therefore, will have to make alternative arrangements from authorized sources for making the water available for the said construction. Therefore, the aforesaid prohibition on use of the underground water for construction purpose does not justify the delay in completion of the construction. In any case, no material has been placed by the opposite party on record to show that efforts were made by it during the relevant period to procure water from alternative sources but it was unable to obtain the water from the said sources. More importantly, in the Buyers Agreement executed between the parties, it was not disclosed to the buyers that since no underground water can be used for construction purpose, the developer will have to arrange water from alternative sources and in case it is not able to arrange water, the construction would be delayed and in that case, it will not be held responsible for the delay in completion of the construction.”

4.       The learned counsel for the OP states on instructions that the construction of the villa has started in December 2016, though she admits that the possession of construction is very slow.  She is not in a position to commit any particular time period for completion of construction and delivery of possession of the villa to the complainant.”

6.      Since the grounds on which the complaint is sought to be contested have already been rejected in Sudhanshu Pokhriyal (supra) and Capt. Gurtaj Singh Sahani  & Anr. Vs Unitech Ltd. & Anr. (supra), the said grounds need not be examined afresh in this complaint.

7.      The learned counsel for the complainant states on instructions on the complainant that she is restricting her claim to the possession of the house allotted to her alongwith compensation in the form of simple interest @8% per annum from the committed date of possession till date of delivery of possession.   The complaint is therefore disposed of with following directions:-

1. The opposite party shall complete the constructions of the villa allotted to the complainant in all respects, obtain the occupancy certificate and offer its possession to her on or before 31.12.2018.

2. The opposite party shall pay compensation to the complainant in the form of simple interest @ 8% per annum from the committed date of possession i.e. w.e.f. 30.02.2014 till the date on which the possession in terms of this order after completing the construction in all respects and obtaining the requisite occupancy certificate is actually offered.

3. Additional amount if any, payable by the complainant to the opposite party shall be adjusted out of the compensation payable to the complainant in terms of this order and the balance amount if any shall be paid to her on or before the date on which the possession in terms of this order is actually offered.

4. The opposite party shall pay sum of Rs.25,000/- as cost of litigation to the complainant.

5. The opposite party shall not create any third party interest in the villa allotted to the complainant till possession in terms of this order is actually delivered to her.